Terms and Conditions

Terms & Conditions

  1. Scope of Work
    • The company will provide services as outlined in the agreed quotation, as per drawings, and specifications. Any additional work requested by the client will be treated as a variation.
  1. Quotations & Pricing
    • Quotes are valid for a specified period (e.g., 30 days).
    • Prices may be subject to change due to material cost increases or unforeseen circumstances.
    • All prices are plus VAT unless otherwise stated
  1. Payment Terms
    • A deposit of 33% is required 2 weeks before work begins.
    • Stage payments may be required generally at a monthly basis
    • Final payment is due upon completion of the work.
    • Late payments may incur interest or penalties.
  1. Variations & Changes
    • Any changes requested by the client must be agreed in writing.
    • Variations may affect both cost and project timeline.
    • Additional charges will apply for extra work outside the original scope.
  1. Project Timeline
    • Estimated start and completion dates will be provided.
    • Delays caused by weather, supply issues, or client changes are not the contractor’s responsibility.
    • The company will aim to complete the work within a reasonable timeframe.
    • Additional works will increase the time line but we will always do our best to complete the works asap
  1. Client Responsibilities
    • The client must provide access to the site during working hours.
    • The client is responsible for obtaining necessary permissions unless otherwise agreed.
    • Utilities (water, electricity) should be available unless specified.
  1. Materials & Workmanship
    • Materials used will be as specified or of similar quality if unavailable.
    • Work will be carried out to industry standards.
    • Substitutions may be made, if necessary, with client approval where possible.
  1. Insurance & Liability
    • The company will maintain appropriate insurance (e.g., public liability).
    • The company is not liable for pre-existing structural issues or hidden defects.
    • Liability is limited to the value of the contract unless otherwise stated.
  1. Health & Safety
    • The company will comply with relevant health and safety regulations.
    • Clients and visitors must follow site safety rules at all times.
  1. Defects & Warranty
    • A defects liability period (is 12 months)
    • The company will rectify defects caused by workmanship within this period.
    • Warranty does not cover misuse, wear and tear, storm damage or third-party damage.
  1. Termination
    • Either party may terminate the contract with written notice under certain conditions.
    • The client must pay for work completed up to the termination date.
  1. Dispute Resolution
    • Disputes should first be resolved through negotiation.
    • If unresolved, mediation or arbitration may be used before legal action.
  1. Force Majeure
    • The company is not liable for delays or failure caused by events beyond its control (e.g., natural disasters, strikes, supply chain disruptions).
  1. Governing Law
    • The contract is governed by the laws of the relevant jurisdiction (e.g., England and Wales).